1. Introduction
The construction sector in Greece experienced a substantial decline after the fiscal crisis of 2008, following the downward trend in GDP and the subsequent financial and banking crisis. However, in recent years, it has managed to recover, especially after 2017, when growth rates were observed in the country [1]. Since then, the number of public works construction contracts has been increasing, and copious amounts of money have been allocated by the country’s public entities operating in the construction sector. As with all construction industries, the Greek construction industry is plagued with delays and cost overruns that inevitably lead to claims and disputes that, in many cases, end up in litigation, which inevitably cost additional money to both disputing parties.
Within this complex professional environment, where different objectives and benefits compete, according to each involved stakeholder’s perspective, conflicts are sure to arise [2]. If these differences cannot be overcome with common courtesy or the use of management skills, they may result in the submission of a claim, i.e., a request for compensation for damages incurred by any party to the contract [3] that if rejected by the other party, result in disputes [4], which are slow to be resolved, especially if they end up in court. Therefore, the submission and rejection of a claim define the start of dispute evolution [5] which may or may not have significant impacts on contract performance. Therefore, identification of the causes of these claims and their impact on the duration, cost, and quality of the final project is expected to facilitate the successful performance of the construction project.
Initially, a literature review was conducted regarding research on claims in the construction industry since 1990. The search was implemented through the Google Scholar platform and through databases such as
Furthermore, the content analysis of the 50 examined articles revealed that four types of data sources were used. Data were obtained from the literature, questionnaire surveys, interviews, case studies, or a combination of these. Their geographical spread is noteworthy as they referred to construction claim research in 19 different countries. This is to be expected as the legal, social, and political environments of construction industries around the world are highly diverse. As a result, the findings of one country cannot necessarily be applied to other countries. As a result, research work on construction contract claims in the Greek construction industry was not found.
During the content analysis, it was discovered that regardless of the scope of the research paper, most provided a list of common causes of claims that were investigated from their point of view. Researchers like Ali et al. [10], Arditi and Pattanakitchamroon [11], and Yusuwan and Adnan [12] focused on one specific cause, i.e., extension of time (EOT) claims, while Ballesteros-Pérez et al. [13] through analyzing severe weather conditions leading to work stoppages and productivity loss leading to project delays created a model that offers advantages for predicting weather-related productivity losses at the design stage.
On the other hand, other researchers examined a significantly greater number of causes of claims (Table 1). For example, Yousefi et al. [14] included sixty risks leading to claims, which they classified into nine categories, i.e., integration, scope, time, procurement, communication, risk, human resource cost, cost, and quality management categories. Using this classification, they developed a model based on the probability impact matrix and used the analytical hierarchy process (AHP) and artificial neural networks (ANNs) to predict the frequency of claims in construction projects. Similarly, Chau [15] created ANN models as a prediction tool prior to litigation for estimating the resolution of a claim. Cakmak and Cakmak [16] used the analytical network process and showed that contractor-related causes of contractual claims and their subcategories are the most common in the Turkish construction industry.
Both Iskandar et al. [17] and Mishmish et al. [3] examined how the ranking of the importance of claims in construction vary between different categories of stakeholders. Their research differed in terms of data sources as Iskandar et al. [17] relied on questionnaires, while Mishmish et al. [3] relied on case studies as well as questionnaires.
The quest of numerous researchers was to determine the most common causes of claims for a particular type of project. For example, Nabi and El-Adaway [18] examined the associations between 40 causes of claims for a specific type of construction, that of modular construction in the United States of America (USA). They found that modular construction disputes are prompted by multiple causes rather than just one cause at a time. Similarly, Bakhary et al. [19] examined the causes of contractual claims in cases of public and private projects in Malaysia’s transport, oil, and gas sectors. They found that lack of awareness among on-site staff to proactively identify contractual claims, lack of access to or unavailability of relevant documents, and conflicts that arise during negotiation between the contracting authority (CA) and the contractor are the main problems associated with the contractual claim management process. Furthermore, Kisi et al. [20] examined transport construction projects in Nepal with data collected from a questionnaire-based investigation. They found that contractual claims related to variations, location, conditions, and delays were the most common.
Finally, Shen et al. [21] examined how contractual claims are managed for diverse types of projects worldwide. They considered external risks (social, political, physical, and financial), the organizational behavior of clients (untimely payments, change orders, inefficient processing), and the definition of the project in the contract (unclear technical specifications, unclear scope of work) as causes of contractual claims. Their study findings suggest that external risk, client organizational behavior, and project definition in the contract can directly influence contractual claims.
One example of research work aiming to bring claim management techniques up to date with the use of digital tools is that of Ibraheem and Mahjoob [22], who showed the potential of building information modelling (BIM) in the prevention of causes of claims related to inaccurate quantity estimates, excessive change orders, errors and design changes, drawing and specification defects, as well as lack of communication between various design disciplines. This was achieved by taking advantage of specific BIM functions such as 3D visualization, clash detection, coordination, and quantity measurement take-off. Before their research, no system was being implemented in Iraq to manage contractual claims, indicating the benefits to be achieved in terms of claim reduction by applying innovative technologies in construction contract management.
For green building projects in Turkey, Mohammadi and Birgonul [7] evaluated the relative importance index (RII) for factors leading to (a) professional liability risks, (b) third-party certification risks, (c) financial risks, and (d) legal contractual risks based on expert opinion and found that legal risks are the ones that cause the contractual claims between the parties involved in sustainable construction projects indicating the significance of being able to identify and assess potential contractual claims in advance through appropriate risk management techniques.
Based on the existing literature described in the previous paragraphs, there is abundant research interest in the causes of contractual claims and the prediction of the probability of their occurrence. However, no relevant recent research examines this issue in the construction industry in Greece. Moreover, even though each study examines similar causes, comparisons of their results are obstructed due to a lack of standard coding. Therefore, after the content analysis of the selected studies, this paper defines a cause of claims breakdown structure (CCBS) that includes the 39 most common causes of claims that are encountered in real projects internationally as found in the literature.
The novelty of this study is that these common causes of claims, as defined by the literature review and content analysis, are further investigated in terms of their probability of occurrence and the perceived impact they have on the project completion time, its total cost, and quality. As a result, a risk assessment tool for claim prevention can be provided for use by practitioners to fill the gap determined by Olalekan et al. [9] in their recent bibliometric review.
Therefore, the research questions (RQ) are:
What is the frequency of occurrence of each cause of contractual claim?
What is the perceived impact of each cause of claims on the project’s duration?
What is the perceived impact of each cause of claims on the project’s final cost?
What is the perceived impact of each cause of claims on the quality of the project?
What are the top five highest risk causes of claims on the overall performance of construction contracts?
Literature review content analysis.
Authors | Year | Data Source 1 | Research Scope | Causes | Country |
---|---|---|---|---|---|
Abdul-Malak et al. [23] | 2002 | LR | Claims management | 0 | |
Aibinu et al. [8] | 2011 | Q/CS | Stakeholder perception | 0 | Singapore |
Ali et al. [10] | 2020 | Q/I/CS | Claims management | 1 | Pakistan |
Al-Sabah et al. [24] | 2003 | LR | Causes of claims | 7 | Kuwait |
Arditi and Pattanakitchamroon [11] | 2006 | LR | Claims management | 1 | N/A |
Bakhary et al. [19] | 2015 | Q | Causes of claims | 8 | Malaysia |
Ballesteros-Pérez [13] | 2017 | LR | Dispute resolution | 1 | Spain |
Barman and Charoenngam [25] | 2017 | CS | Claims management | 6 | UK |
Cakmak and Cakmak [16] | 2014 | Q/CS | Causes of claims | 28 | Turkey |
Chan and Suen [26] | 2005 | Q | Causes of claims and dispute resolution | 16 | China |
Chan et al. [27] | 2006 | I | Dispute resolution | 2 | Hong Kong |
Chaphalkar et al. [4] | 2015 | CS | Causes of claims | 10 | India |
Chau [15] | 2007 | LR | Dispute resolution | 24 | Hong Kong |
Cheung and Pang [28] | 2013 | LR | Causes of claims and dispute resolution | 8 | Hong Kong |
Cheung and Suen [29] | 2002 | LR/I | Dispute resolution | 0 | Hong Kong |
Cheung et al. [30] | 2019 | Q | Dispute resolution | 56 | Hong Kong |
Diekmann and Girard [31] | 1995 | Q/CS | Claims management | 0 | USA |
Gardiner and Simmons [32] | 1998 | I/CS | Causes of claims | 3 | UK |
Gould [33] | 1998 | Q | Dispute resolution | 0 | UK |
Ho and Liu [34] | 2004 | LR | Claims management | 0 | |
Ibraheem and Mahjoob [22] | 2021 | Q/CS | Causes of claims | 16 | Iraq |
Ilter and Bakioglu [35] | 2018 | CS | Claims management | 19 | Turkey |
Iskandar [17] | 2021 | Q | Causes of claims | 43 | Indonesia |
Jahren and Dammeier [36] | 1990 | I | Claims management | 7 | USA |
Kartam [37] | 1999 | LR | Claims management | 0 | |
Kilian et al. [38] | 2005 | CS | Causes of claims | 7 | USA |
Kisi et al. [20] | 2020 | Q | Dispute resolution | 7 | International |
Kululanga et al. [39] | 2001 | Q/CS | Claims management | 0 | Malawi |
Kumaraswamy [40] | 1998 | LR/Q/ CS | Causes of claims | 29 | Hong Kong |
Mishmish and El-Sauegh [3] | 2018 | Q/CS | Causes of claims | 16 | UAE |
Mitropoulos and Howell [6] | 2001 | LR | Dispute Development Process | 14 | USA |
Mohammadi and Birgonu [7] | 2016 | Q | Investment Risks | 4 | Turkey |
Nabi and El-Adaway [18] | 2022 | CS | Causes of claims | 40 | USA |
Olalekan et al. [9] | 2021 | LR | Bibliometric Review of Construction Claim Research | 0 | International |
Ren and Anumba [41] | 2002 | LR | Claims Negotiation | 0 | |
Ren et al. [42] | 2003 | CS | Claims Negotiation | 2 | |
Ren et al. [43] | 2002 | LR | Claims Negotiation | 4 | |
Scott and Harris [44] | 2004 | Q/I | Claims management | 4 | UK |
Semple et al. [45] | 1994 | CS | Causes of claims | 4 | Canada |
Shen et al. [21] | 2017 | Q | Claims management | 10 | International |
Stamatiou et al. [46] | 2019 | LR | Claims management | 19 | Greece/UK |
Treacy [47] | 1995 | LR | Dispute resolution | 0 | USA |
Vidogah and Ndekugri [48] | 1997 | Q/I/CS | Claims management | 4 | UK |
Viswanathan et al. [49] | 2020 | LR/Q | Causes of claims | 14 | India |
Wong and Maric [50] | 2016 | CS | Causes of claims | 7 | Australia |
Yogeswaran et al. [51] | 1998 | CS | Causes of claims | 11 | Hong Kong |
Yousefi et al. [14] | 2016 | LR/CS | Causes of claims | 60 | Iran |
Yuan and Ma [52] | 2012 | LR | Claims Negotiation | 0 | |
Yusuwan and Adnan [12] | 2013 | Q | Causes of claims | 1 | Malaysia |
Zaneldin [53] | 2006 | Q/CS | Causes of claims | 26 | UAE |
1 LR = Literature Review; CS = Case Studies; I = Interviews; Q = Questionnaire.
The present study follows a mixed-methods research approach using a questionnaire addressed to 22 professional engineers who have been active in Greece for the last few years and engage in public procurement for construction projects from different workplaces. Data from 50 articles examining the causes of contractual claims in different countries for construction projects in public and private sectors were used to create the questionnaire. Data analysis included descriptive statistical analysis, reliability testing, use of relative importance index, and risk analysis.
The rest of this paper includes Section 2, which presents the methods for development of the cause of claims breakdown structure (CCBS), data collection, and analysis. The results are presented and discussed in Section 3. Finally, Section 4 presents the conclusions and limitations of the research, plus recommendations for future research.
2. Research Methods
2.1. Cause of Claims Breakdown Structure (CCBS)
The studies in Table 1 defined a series of causes of claims obtained from the literature reviews, questionnaire surveys, and/or case studies and then proceeded to categorize and rank them in various ways. The number of causes each researcher utilizes and analyzes also differs. Developing a unified classification of causes of claims in construction contracts and creating a common codification can provide a basis for comparing the results of international research. Eight studies examined over twenty causes, while twenty studies considered less than ten causes (Table 1).
After the initial collection and production of a study versus causes table with 539 causes (rows) and the 50 studies (columns) and following the removal of causes with the same name or grouping of others with similar meanings, they were consolidated to obtain a final list of 39 causes each appearing at least once and up to 23 times in the selected studies.
Causes of claims, like all risk sources, can be structured and codified to provide a standard representation to help understand, manage, and communicate on a project and industry level while allowing easy comparison between scientific research endeavors. A risk breakdown structure (RBS) is the categorization of risk sources in a hierarchical structure [54]. As a result, 39 factors were coded and classified in the CCBS, as shown in Figure 1. It provides a comprehensive yet detailed view of the hierarchy of the predominant causes of claims examined in the selected studies. Based on Cakmak and Cakmak’s [16] categorization, the 39 factors were classified into the following 7 categories relating to the CA, the contractor, the design, the contract, human behavior, the project itself, and external factors.
2.2. Data Collection
The questionnaire examined the opinions of experts on 39 common causes of contractual claims in public construction contracts according to: (a) the frequency of their occurrence, (b) the perceived impact they have on the time to complete the project, (c) the perceived impact on the total cost of the project, and (d) the perceived impact on the quality of the final project.
A mixed-methods research approach [55] was applied that integrated qualitative data (opinions of experts) in quantitative form (based on closed-ended responses to a relevant survey) with quantitative research analysis methods (Likert scale ratings, relative importance index, and risk value). It was designed to quantitatively describe a population’s trends, attitudes, or opinions [55] based on the qualitative views of the expert participants instead of actual data from claims made in real projects. This survey research method can be called the ‘knowledge mining’ method that has been used in construction management research by the authors and others to determine expert opinion and practitioners’ insights on delay factors [56], cost escalation [57], contract types [58], project procurement systems [59,60], project managers’ attributes [61], barriers to energy upgrading of buildings [62], safety control [63], as well as for claim management problems [19].
The questions were mostly multiple-choice, closed-ended questions. The first part of the questionnaire consisted of 11 questions that relate to the demographic and personal data of the survey participants, who are active engineers of different specializations. The second part included an assessment of the cause of contractual claims in public works’ contracts in terms of the four variables (frequency of occurrence, impact on project completion time, total project cost, and quality of the final project). This section uses the five-point Likert scale, with the assessment being made using two ways of scoring:
1—Never, 2—Rarely, 3—Often, 4—Many times and 5—Always (RQ1).
1—Not at all, 2—Very little, 3—A little, 4—A lot, and 5—Very much (RQ2–4).
Participants expressed their opinions on the level of agreement for each variable using the above scales, which were later transformed into numerical scores with values from 1 to 5 in SPSS. In addition, the questionnaire included an open-ended question on ways to address or reduce the incidence of claims in the management of public construction contracts, which was not compulsory and was answered by 11 out of 22 sample participants.
From the outset, the questionnaire was chosen to be addressed to experts rather than the general population because of the nature and scope of the subject matter, which requires knowledge and experience in public works’ contracting. Professionals with knowledge of public construction project management have also faced contractual claims and disputes and can objectively capture the root causes of construction contractual claims. It should be noted that the corresponding author, who has decades of personal experience in claim management for highway construction contracts, retained numerous experienced contacts in the industry to whom a private direct message was sent to inform them of the purpose of the survey. Thus, this convenience sampling method [64] collected 22 responses by posting on the LinkedIn social media platform and by sending 36 personal invitations through Meta Messenger and Viber. The questionnaires were distributed via Google Forms and were completed and submitted anonymously from January to February 2023.
2.3. Data Analysis Methodology
The data from the questionnaire survey were analyzed using the IBM SPSS statistical tool. For the Likert scale questions, it was found that the mean and standard deviation of the variables were not sufficient, as most of the results were near the neutral answer. Thus, it was chosen to perform the subsequent data analysis by calculating each variable’s relative importance index (RII) and to use the results to carry out a risk analysis by calculating the resulting risk value (RV) to measure the risk of each cause of contractual claim on the duration, time, quality, and overall performance of the final project.
The RII has been used in construction management research to assess the severity of identified delay factors on project duration and cost escalation [65,66,67,68], to rank the significance of contributing factors to accidents [63], and to conduct meta-analyses of data from multiple studies [69].
In this study, the RII was calculated using Microsoft Excel according to Equation (1), adapted from Holt [70], for each of the 156 variables (39 causes × 4 research questions) rated on a five-point Likert scale.
(1)
where-
m = number of integers on the response scale (in this case 5);
-
Pi = takes values 1 to 5 in increasing frequency/severity;
-
Ui = number of respondents that selected Pi;
-
N = Total number of respondents (N = 22);
-
n = maximum value of maximum rating (in this case 5).
It should be clarified that all questions were compulsory (except the open-ended question), and thus, there were no blank answers. As a result, the RII can take values from 0 to 1 and is therefore taken as a measure of the probability of occurrence of a particular cause of claims. In this case, the lowest possible value is 0.2 since in the worst-case scenario of all respondents choosing Never or Not at all, the formula produces an RII value of 0.2.
The risk analysis complements the RII analysis, as the RII method, although effective in ranking the various causes of claims in terms of their perceived frequency of occurrence, does not take into account the magnitude of their impact or the vulnerability that a particular construction project may have for each cause of claim and thus does not provide all the knowledge required to conduct contractual claim risk analysis for a new project [68].
Risks on the successful outcome of a construction contract correspond to uncertain events or situations which, if they manifest, may have a positive or negative impact on the objectives of the construction project [54]. In this case, the causes of claims are risks that, if they occur, will have a negative impact on the objective of completing the project within the planned schedule, budgeted cost, and expected quality. In this context, the risk is considered a multidimensional quantity approximated by a point estimate as the expected value resulting from multiplying the probability of the cause of the claim occurring (P) by its consequence, impact, or severity (S), given that it has taken place. Thus, the risk value (RV) of the cause of a claim can be calculated using Equation (2) [54]:
RV = Pi × Si,(2)
3. Results and Discussion
3.1. Demographic and Personal Characteristics
Table 2 and Table 3 present the demographic data and experience of the 22 survey participants. All participants have experience in public contract management either as engineers of the construction contractor or as engineers of the CA or both. Furthermore, 17 participants responded that they have experience in construction contract management as engineers employed by the contractor, and 16 people responded that they have experience in construction contract management as supervising engineers for the CA (72.73%), and 50% had experience in both. Overall, it was judged that the sample was quite experienced in managing public construction contracts in the capacity of construction contractor engineer and the capacity of CA engineer.
3.2. Relative Importance Indices (RII)
Cronbach’s alpha reliability index was calculated for each of the four research questions by including the thirty-nine tested causes derived from the literature in each of them. A high internal consistency for the data set was observed (Table 4) as the Cronbach’s alpha index takes values greater than 0.7 in each case [71].
The evaluation of the resulting RII was made by considering the following transformation scheme adapted from Chen et al. [72] to suit the rating scale employed in the questionnaire.
-
High for values greater than 0.8;
-
High-medium for values between 0.6 and 0.8;
-
Medium for values between 0.4 and 0.6;
-
Low for values between 0.2 and 0.4.
Table 5 presents the mean, standard deviation, and RII index of the respondents’ answers to RQ1–RQ4 as well as the number of times each cause appeared in the 50 studies. First, regarding the frequency of occurrence of the examined causes of claims as they have experienced them during their professional career, we observed that in the Greek construction industry, the most frequently occurring cause is “Changes in quantities, work, or scope (A1)” with an RII = 0.75. Next, the results relating to RQ2 showed the most significant impact on the project duration is caused by “Financial failure of the contractor (B3)” with an RII = 0.78. Furthermore, regarding the perceived severity of the impact of the various causes of claims on the total project cost (RQ3), we observed that the cause with the most significant impact on the total project cost (RII = 0.79) is “Inflation/Price Rises (G3)”. Finally, from the responses to RQ4, it is observed that in the Greek construction sector, the cause of contractual claims with the greatest impact on the quality of the final project is “Time extensions (B2)” (RII = 0.81).
Table 6 depicts the causes ranked in the top ten for each research question, i.e., the most frequent causes and the ten causes with the most severe perceived impact on the final duration, cost, and quality. It is interesting to note that while “Changes in quantities, work or scope (A1)” is the most probable cause, it is perceived to have a significant impact (>0.6) on cost (RIIC = 0.75), duration (RIID = 0.78), and not on quality. On the other hand, the cause perceived to have the greatest impact on the quality of the project “Time extensions (B2)” is not in the top 10 frequent causes at all. Finally, the three causes of claims rated in the top ten in all four categories are “Payment delays (A5)”, “Design quality deficiencies or errors (C1)”, and “Inflation/price increases (G3)”. Therefore, as these three causes are perceived by the experts as having a significant impact on time, cost, and quality, while also considered to have a high frequency of occurrence, it is expected that they will emerge in the top 10 highest risk causes of claims that should be avoided by public work clients. The next section describes the results of the risk analysis on all 39 causes.
3.3. Risk Analysis
The degree of risk refers not only to the probability of something happening but also to the impact of the risk in question. The RII index calculated for the frequency of occurrence of the causes as rated by the respondents (Table 6) was used to determine the (P) probability values. The severity (S) value is subjective and varies according to the risk aversion of the decision maker and the actual conditions for each project [68]. However, in the case of this research, the RII indicators obtained by processing the respondents’ answers on the extent to which they believe that each cause impacts the duration (RIIid), cost (RIIic), and quality of the final project (RIIiq) were calculated (Table 6).
The degree of risk in terms of time (RVt), cost (RVc), and quality (RVq) of the final project was then calculated as follows:
RVD = Pi × Sid = RIIi × RIIid,(3)
RVC = Pi × Sic = RIIi × RIIic,(4)
RVQ = Pi × Siq = RIIi × RIIiq(5)
Table 7 presents the risk values (RVD, RVC, RVQ) and their ranking according to the calculated risks on project duration (Rank RVD), total project cost (Rank RVC), and project quality (Rank RVQ). The three causes with the highest risk value in terms of project duration are “Changes in the quantities, work, or scope (A1), “Financial failure of the contractor (B3)”, and “Delays in work progress (B1)”. Of the three, only “Financial failure of the contractor (B3)” was perceived as having the greatest impact on duration while “Changes in quantities, work or scope (A1)” ranked sixth with a significant RIID value of 0, 75, and “Delays in work progress (B1)” ranked third with an RIID = 0.76 but with medium to high probability of occurrence RIIi = 0.66. Obviously, changes in scope take time to take effect and if design changes are required, in cases of increased quantities will also require additional time to be completed. Similarly, financial problems endured by the contractor will lead them to adjust their resource planning which will inevitably take their toll on project progress. Finally, it goes without saying that any delays on the progress of work will have detrimental effects on project completion.
The riskiest causes of claims regarding the increase in project costs are, again, “Changes in quantities, work, or scope (A1)”. Notably, instead of “Inflation/Price Increases (G3)” emerging as the second riskiest cause on cost increase which was perceived with the highest impact on cost, this time, in second place is “Design quality deficiencies or errors (C1), and in third place is “Payment delays (A5)” in terms of risk value on cost increases. It is found that change orders and design deficiencies are risks with a greater potential to lead to project cost overruns than causes related directly to payment delays. Finally, to prevent significant impacts on the quality of projects, mitigation measures to prevent claims arising from “Design quality deficiencies or errors (C1), “Payment delays (A5)”, and “Changes in quantities, work or scope (A1)” should be implemented.
An attempt is then made to synthesize the results to determine which causes have the highest overall risk level considering all three risk values (RVD, RVC, RVQ). Based on the results of the individual RVs for the three variables considered, weight is given to each risk level by considering two scenarios. The first probability scenario (Scenario 1) assumes a weighting factor of 70% for the project duration (wd), 15% for the impact on the total cost (wc), and another 15% for the effect on the quality of the final project (wq). That is, the decision maker, in this case, considers the impact on duration more important than the impact on cost and time. The results differ in the case of the second scenario (Scenario 2), in which the weighting factor for the impacts on duration, cost, and quality of the final project are considered equal and thus calculated at 33.3% for each variable. Table 7 presents the results of Scenario 1 and Scenario 2 with the ranking of each cause according to the resulting total risk value (TRV) as follows:
TRVi = wd × RVDi + wc × RVCi + wq × RVQi,(6)
We observe that both scenarios agree on the top five most dangerous causes of contractual claims that affect overall project performance although in a slightly different order. These are once again “Changes in quantities, work, or scope (A1)”, followed by “Design quality deficiencies or errors (C1), “Payment delays (A5)”, “Delays in work progress (B1)”, and the “Financial failure of the contractor (B3)”.
3.4. Expert Proposals for Mitigation Measures
The questionnaire included an open-ended question on the participants’ views on how claims can be addressed or reduced in the management of public construction contracts. Participant P3 believes that one way is “to better inform potential contractors about the project and the site conditions during the formulation of the financial offer, and another is to promote a team spirit between the contractor and the contracting authority”.
According to Participant P7, one way is to “draw up detailed rules, specifications and studies”. Similarly, participant P11 considers that the solution is “better designs and more elaborate contract documents”. The twelfth participant, P12, suggests more “professionalism and proper training”. Participants P14 and P16 mention as a way of resolution “the most comprehensive designs possible, timely giving possession of the land, ensuring financial flow throughout the project, timely response by the CA to problems” and “better designs with supervision by the designer during construction”, respectively.
There is another view expressed by the thirteenth participant (P13) that “better preparation of the pre-contractual stage for all kinds of licensing and anything related” is needed. Participant P18 suggests “tendering with a design-build system”. In contrast, participant P20, based on their experience in the execution of public works, considers that “the Amicable Settlement Committee or as it is now called Arbitration can help all stakeholders” and believes “the activation of article 176 of Law 4412/16 is necessary for a wider range of projects and not only for projects above 10.000.000€”. This stipulation refers to the procedures for applying arbitration as a dispute resolution method instead of the administrative and judicial procedures that can be used in all cases of public works’ contracts in Greece.
The above suggestions provided by the respondents on how claims can be addressed or reduced in the management of public construction contracts were given without knowledge of the results of the risk assessment conducted based on their individual ratings of frequency of occurrence and severity of impact. Of all the suggestions made, only four participants indicated mitigation measures related to four of the five highest risk causes identified in this study. Suggestions were made by P7, P11, P14, and P16 to prevent claims due to “Changes in quantities, work or scope (A1)” and “Design quality deficiencies (C1)” by “drawing up detailed rules, specifications and studies”, providing “better designs and more elaborate contract documents,” or “the most comprehensive designs possible”, and ensuring “better designs with supervision by the designer during construction”. Also, P14 considered it necessary to “ensure financial flow throughout the project” as a mitigation measure for “Payment delays (A5) ” that will inevitably facilitate prevention of “Financial failure of the contractor (B3)”. No suggestions were made to prevent “Delays in work progress (B1)” directly by any of the participants.
4. Conclusions
Based on the calculated RII values from the opinions of experts in the field, this paper proposes probability and severity of impact values for 39 common causes of claims in the public construction industry in Greece. These can be applied for the calculation of their RVs to guide Greek stakeholders in public construction contracts to plan mitigation measures for the consequences of contractual claims on construction contract performance. From the ranking of the causes based on the TRV, the causes of contractual claims that most affect the performance of construction projects in Greece are highlighted. In response to RQ 5, it is shown that the top five highest risk causes of contractual claims in the Greek construction industry that affect overall project performance are “Changes in quantities, work, or scope (A1)”, followed by “Design quality deficiencies or errors (C1), “Payment delays (A5)”, “Delays in work progress (B1)”, and the “Financial failure of the contractor (B3)”.
This research article contributes to the international literature on the causes of contractual claims in construction projects as it pioneers through its simultaneous examination of the views of experts on the frequency of occurrence of causes of contractual claims and their perceived impact on the time, total cost, and quality of the final project, for which there is a research gap in the literature. In addition, it defines a cause of claims breakdown structure (CCBS) that includes the most common causes of claims that are encountered in real projects internationally, as found in the literature, which international researchers can use to facilitate comparison of results to provide global conclusions. The limitations of this study are that it needs to be more focused on specific construction types and that it is based only on expert opinion. It should, therefore, be verified based on existing project claims data and with a questionnaire survey directed to a greater number of stakeholders in the construction industry. The results could then be further analyzed using factor analysis and analysis of variance to evaluate the independence or not of the individual causes of claims as well as differences in opinions between groups of respondents (CA, contractor, designer). In addition, this study could be further expanded to include expert opinion and data from private projects and private clients to see if significant differences occur between public and private construction projects.
Nevertheless, the results of this study can be used as a springboard for the development of an optimal streamlined dispute prevention method for which a gap in the literature remains [9]. The research team envisages that this can be achieved by the adoption of advanced technologies to address the above-flagged issues. By combining BIM, Blockchain, and smart contracts, progress payments can be automated [73,74,75,76] and delays in work progress and associated EOT claims can be better managed [10]. Additionally, the utilization of specific BIM functions, such as 3D visualization, clash detection, coordination, and quantity measurement take-off, can ensure minimization of changes in quantities, work, or scope and design quality deficiencies or errors [22]. Finally, provisions in the tender procedures to prevent the selection of a contractor with indications of financial difficulties can be implemented to avoid claims caused by the financial failure of the contractor.
Conceptualization, F.A.; methodology, F.A.; software, A.V.T.; validation, F.A. and A.V.T.; formal analysis, A.V.T.; investigation, A.V.T.; data curation, A.V.T.; writing—original draft preparation, F.A. and A.V.T.; writing—review and editing, F.A. All authors have read and agreed to the published version of the manuscript.
Data are available on request with privacy restrictions. The data are not publicly available due to GDPR constraints.
The authors declare no conflicts of interest.
Footnotes
Disclaimer/Publisher’s Note: The statements, opinions and data contained in all publications are solely those of the individual author(s) and contributor(s) and not of MDPI and/or the editor(s). MDPI and/or the editor(s) disclaim responsibility for any injury to people or property resulting from any ideas, methods, instructions or products referred to in the content.
Demographic data of the sample.
Sex: | Men (68.2%), Women (31.8%) |
Age: | 26–34 (4.5%), 35–44 (9.1%), 45–54 (45.5%), 55–64 (31.8%), 65 and over (9.1%) |
Highest Academic Degree: | First University Degree (45.5%), Postgraduate Degree (45.5%), PhD (9.1%) |
Profession: | Civil Engineer (72.7%), Architect (4.5%), Electrical Engineer (4.5%), Other (18.2%) |
No of participants experienced in different types of construction projects.
Construction Type | No. of Experienced Participants | Construction Type | No. of Experienced Participants |
---|---|---|---|
Buildings | 15 (68.18%) | Ports | 5 (22.73%) |
Roads | 19 (86.36%) | Airports | 4 (18.18%) |
Water networks | 17 (77.27%) | Railway | 4 (18.18%) |
Sewage networks | 13 (59.09%) | Metro | 3 (13.64%) |
Cronbach’s alpha reliability index.
Research Question | Degree of Reliability (Cronbach’s Alpha) | Research Question | Degree of Reliability (Cronbach’s Alpha) |
---|---|---|---|
RQ1 Frequency of occurrence | 0.949 | RQ3 Severity of impact on cost | 0.985 |
RQ2 Severity of impact on duration | 0.977 | RQ4 Severity of impact on quality | 0.984 |
Statistical results of research questions 1 to 4.
CCBS Code | Νο. of Occurrences in Literature | RQ1 | RQ2 | RQ3 | RQ 4 | ||||||||
---|---|---|---|---|---|---|---|---|---|---|---|---|---|
Mean | Sd. | RIIi | Mean | Sd. | RIIid | Mean | Sd. | RIIic | Mean | Sd. | RIIip | ||
A1 | 23 | 3.73 | 1.03 | 0.75 | 3.77 | 0.61 | 0.75 | 3.91 | 0.87 | 0.78 | 2.82 | 0.80 | 0.56 |
A2 | 9 | 3.05 | 1.13 | 0.61 | 3.82 | 1.10 | 0.76 | 3.23 | 0.97 | 0.65 | 2.45 | 0.67 | 0.49 |
A3 | 18 | 2.41 | 0.85 | 0.48 | 3.05 | 0.95 | 0.61 | 3.00 | 0.98 | 0.60 | 2.55 | 0.91 | 0.51 |
A4 | 6 | 2.68 | 0.89 | 0.54 | 2.91 | 1.02 | 0.58 | 3.00 | 1.07 | 0.60 | 2.64 | 0.95 | 0.53 |
A5 | 12 | 3.23 | 0.81 | 0.65 | 3.86 | 1.04 | 0.77 | 3.59 | 1.05 | 0.72 | 3.23 | 0.87 | 0.65 |
A6 | 7 | 3.23 | 1.02 | 0.65 | 3.36 | 1.05 | 0.67 | 3.50 | 1.01 | 0.70 | 2.91 | 1.07 | 0.58 |
A7 | 3 | 3.14 | 0.83 | 0.63 | 3.23 | 0.81 | 0.65 | 3.23 | 0.92 | 0.65 | 2.64 | 0.49 | 0.53 |
B1 | 19 | 3.32 | 0.72 | 0.66 | 3.82 | 0.85 | 0.76 | 3.41 | 0.96 | 0.68 | 2.86 | 0.94 | 0.57 |
B2 | 17 | 3.41 | 0.96 | 0.51 | 3.91 | 0.87 | 0.61 | 3.18 | 0.91 | 0.65 | 2.73 | 1.03 | 0.81 |
B3 | 6 | 2.82 | 0.73 | 0.68 | 3.82 | 0.91 | 0.78 | 3.27 | 1.03 | 0.64 | 3.45 | 1.14 | 0.55 |
B4 | 12 | 2.18 | 0.66 | 0.56 | 3.68 | 0.84 | 0.76 | 3.36 | 1.09 | 0.65 | 3.55 | 1.14 | 0.69 |
B5 | 5 | 2.27 | 0.70 | 0.44 | 3.18 | 1.05 | 0.74 | 3.05 | 1.09 | 0.45 | 3.09 | 1.11 | 0.71 |
B6 | 8 | 3.73 | 1.03 | 0.45 | 3.77 | 0.61 | 0.64 | 3.91 | 0.87 | 0.61 | 2.82 | 0.80 | 0.62 |
B7 | 8 | 3.05 | 1.13 | 0.51 | 3.82 | 1.10 | 0.64 | 3.23 | 0.97 | 0.69 | 2.45 | 0.67 | 0.61 |
B8 | 4 | 2.41 | 0.85 | 0.50 | 3.05 | 0.95 | 0.63 | 3.00 | 0.98 | 0.60 | 2.55 | 0.91 | 0.59 |
B9 | 3 | 2.68 | 0.89 | 0.36 | 2.91 | 1.02 | 0.55 | 3.00 | 1.07 | 0.56 | 2.64 | 0.95 | 0.52 |
B10 | 16 | 3.23 | 0.81 | 0.45 | 3.86 | 1.04 | 0.60 | 3.59 | 1.05 | 0.61 | 3.23 | 0.87 | 0.61 |
C1 | 13 | 3.23 | 1.02 | 0.65 | 3.36 | 1.05 | 0.75 | 3.50 | 1.01 | 0.76 | 2.91 | 1.07 | 0.74 |
C2 | 11 | 3.14 | 0.83 | 0.52 | 3.23 | 0.81 | 0.66 | 3.23 | 0.92 | 0.64 | 2.64 | 0.49 | 0.67 |
C3 | 3 | 3.32 | 0.72 | 0.51 | 3.82 | 0.85 | 0.65 | 3.41 | 0.96 | 0.60 | 2.86 | 0.94 | 0.65 |
D1 | 12 | 3.41 | 0.96 | 0.49 | 3.91 | 0.87 | 0.63 | 3.18 | 0.91 | 0.61 | 2.73 | 1.03 | 0.60 |
D2 | 8 | 2.82 | 0.73 | 0.53 | 3.82 | 0.91 | 0.67 | 3.27 | 1.03 | 0.63 | 3.45 | 1.14 | 0.60 |
D3 | 8 | 2.18 | 0.66 | 0.44 | 3.68 | 0.84 | 0.58 | 3.36 | 1.09 | 0.55 | 3.55 | 1.14 | 0.53 |
D4 | 4 | 2.27 | 0.70 | 0.45 | 3.18 | 1.05 | 0.61 | 3.05 | 1.09 | 0.55 | 3.09 | 1.11 | 0.52 |
D5 | 11 | 2.55 | 0.80 | 0.43 | 3.18 | 0.91 | 0.63 | 3.45 | 1.14 | 0.61 | 3.05 | 1.05 | 0.57 |
E1 | 6 | 2.50 | 0.86 | 0.45 | 3.14 | 1.04 | 0.61 | 3.00 | 1.16 | 0.63 | 2.95 | 1.13 | 0.56 |
E2 | 16 | 1.82 | 0.73 | 0.45 | 2.73 | 1.03 | 0.63 | 2.82 | 1.01 | 0.63 | 2.59 | 1.10 | 0.57 |
E3 | 6 | 2.23 | 0.69 | 0.44 | 3.00 | 1.02 | 0.62 | 3.05 | 1.13 | 0.62 | 3.05 | 1.09 | 0.56 |
F1 | 13 | 2.55 | 0.86 | 0.51 | 3.05 | 0.79 | 0.67 | 3.23 | 0.97 | 0.62 | 4.05 | 1.17 | 0.61 |
F2 | 5 | 3.23 | 0.75 | 0.56 | 3.77 | 0.97 | 0.70 | 3.82 | 1.01 | 0.69 | 3.68 | 1.25 | 0.60 |
G1 | 11 | 2.59 | 0.91 | 0.56 | 3.32 | 1.00 | 0.62 | 3.18 | 1.05 | 0.66 | 3.64 | 1.29 | 0.60 |
G2 | 9 | 2.55 | 0.80 | 0.47 | 3.23 | 1.19 | 0.61 | 3.00 | 1.07 | 0.63 | 3.27 | 1.32 | 0.53 |
G3 | 6 | 2.45 | 1.06 | 0.56 | 3.14 | 1.13 | 0.71 | 3.05 | 1.05 | 0.79 | 3.00 | 1.16 | 0.66 |
G4 | 6 | 2.64 | 0.90 | 0.48 | 3.36 | 1.22 | 0.62 | 3.14 | 1.08 | 0.66 | 3.00 | 1.31 | 0.57 |
G5 | 7 | 2.18 | 0.96 | 0.49 | 2.91 | 0.97 | 0.58 | 2.77 | 1.07 | 0.59 | 2.64 | 1.05 | 0.55 |
G6 | 6 | 2.23 | 0.87 | 0.49 | 3.05 | 0.90 | 0.70 | 2.77 | 0.81 | 0.72 | 2.59 | 0.91 | 0.61 |
G7 | 3 | 2.14 | 0.83 | 0.42 | 3.14 | 1.17 | 0.55 | 3.05 | 1.05 | 0.55 | 2.86 | 1.17 | 0.53 |
G8 | 2 | 2.23 | 0.87 | 0.45 | 3.05 | 1.21 | 0.62 | 3.14 | 1.17 | 0.62 | 2.82 | 1.01 | 0.54 |
G9 | 2 | 2.27 | 0.83 | 0.47 | 3.14 | 1.21 | 0.62 | 3.14 | 1.21 | 0.58 | 2.86 | 0.99 | 0.51 |
Top ten causes of claims in terms of frequency and severity of impact on duration, cost, and quality.
Freq. | RIIi | Rank | Duration | RIIid | Rank | Cost | RIIic | Rank | Quality | RIIiq | Rank |
---|---|---|---|---|---|---|---|---|---|---|---|
A1 | 0.75 | 1 | B3 | 0.78 | 1 | G3 | 0.79 | 1 | B2 | 0.81 | 1 |
B3 | 0.68 | 2 | A5 | 0.77 | 2 | A1 | 0.78 | 2 | C1 | 0.74 | 2 |
B1 | 0.66 | 3 | B1 | 0.76 | 3 | C1 | 0.76 | 3 | B5 | 0.71 | 3 |
A5 | 0.65 | 4 | A2 | 0.76 | 3 | A5 | 0.72 | 4 | B4 | 0.69 | 4 |
A6 | 0.65 | 4 | B4 | 0.76 | 3 | G6 | 0.72 | 4 | C2 | 0.67 | 5 |
C1 | 0.65 | 4 | A1 | 0.75 | 6 | A6 | 0.7 | 6 | G3 | 0.66 | 6 |
A7 | 0.63 | 7 | C1 | 0.75 | 6 | F2 | 0.69 | 7 | A5 | 0.65 | 7 |
A2 | 0.61 | 8 | B5 | 0.74 | 8 | B7 | 0.69 | 7 | C3 | 0.65 | 7 |
B4 | 0.56 | 9 | G3 | 0.71 | 9 | B1 | 0.68 | 9 | B6 | 0.62 | 9 |
F2 | 0.56 | 9 | F2 | 0.7 | 10 | G1 | 0.66 | 10 | G6 | 0.61 | 10 |
G1 | 0.56 | 9 | G6 | 0.7 | 10 | G4 | 0.66 | 10 | B7 | 0.61 | 10 |
G3 | 0.56 | 9 | F1 | 0.61 | 10 | ||||||
B10 | 0.61 | 10 |
Ranking by RV on project time, cost, and quality.
CCBS Code | RVD | Rank RVD | RVC | Rank RVC | RVQ | Rank RVQ | TRV1 | Rank TRV1 | TRV2 | Rank TRV2 |
---|---|---|---|---|---|---|---|---|---|---|
A1 | 0.56 | 1 | 0.59 | 1 | 0.42 | 3 | 0.54 | 1 | 0.52 | 1 |
A2 | 0.46 | 6 | 0.40 | 9 | 0.30 | 19 | 0.43 | 7 | 0.39 | 9 |
A3 | 0.29 | 25 | 0.29 | 26 | 0.24 | 33 | 0.28 | 25 | 0.28 | 28 |
A4 | 0.31 | 21 | 0.32 | 18 | 0.29 | 23 | 0.31 | 20 | 0.31 | 20 |
A5 | 0.50 | 4 | 0.47 | 3 | 0.42 | 2 | 0.48 | 4 | 0.46 | 3 |
A6 | 0.44 | 7 | 0.46 | 4 | 0.38 | 6 | 0.43 | 6 | 0.42 | 6 |
A7 | 0.41 | 9 | 0.41 | 8 | 0.33 | 13 | 0.40 | 10 | 0.38 | 10 |
B1 | 0.50 | 3 | 0.45 | 5 | 0.38 | 7 | 0.47 | 5 | 0.44 | 5 |
B2 | 0.31 | 22 | 0.33 | 17 | 0.41 | 4 | 0.33 | 17 | 0.35 | 12 |
B3 | 0.53 | 2 | 0.44 | 7 | 0.37 | 8 | 0.49 | 2 | 0.45 | 4 |
B4 | 0.43 | 8 | 0.36 | 12 | 0.39 | 5 | 0.41 | 8 | 0.39 | 8 |
B5 | 0.33 | 19 | 0.20 | 39 | 0.31 | 16 | 0.30 | 23 | 0.28 | 26 |
B6 | 0.29 | 27 | 0.27 | 30 | 0.28 | 24 | 0.28 | 26 | 0.28 | 25 |
B7 | 0.33 | 18 | 0.35 | 14 | 0.31 | 17 | 0.33 | 18 | 0.33 | 17 |
B8 | 0.32 | 20 | 0.30 | 22 | 0.30 | 21 | 0.31 | 21 | 0.30 | 21 |
B9 | 0.20 | 39 | 0.20 | 38 | 0.19 | 39 | 0.20 | 39 | 0.20 | 39 |
B10 | 0.27 | 36 | 0.27 | 30 | 0.27 | 25 | 0.27 | 33 | 0.27 | 30 |
C1 | 0.49 | 5 | 0.49 | 2 | 0.48 | 1 | 0.49 | 3 | 0.49 | 2 |
C2 | 0.34 | 14 | 0.33 | 16 | 0.35 | 10 | 0.34 | 14 | 0.34 | 14 |
C3 | 0.33 | 17 | 0.31 | 21 | 0.33 | 14 | 0.33 | 19 | 0.32 | 18 |
D1 | 0.31 | 23 | 0.30 | 23 | 0.29 | 22 | 0.31 | 22 | 0.30 | 22 |
D2 | 0.36 | 12 | 0.33 | 15 | 0.32 | 15 | 0.35 | 13 | 0.34 | 15 |
D3 | 0.26 | 37 | 0.24 | 36 | 0.23 | 37 | 0.25 | 37 | 0.24 | 37 |
D4 | 0.27 | 32 | 0.25 | 35 | 0.23 | 36 | 0.26 | 36 | 0.25 | 36 |
D5 | 0.27 | 35 | 0.26 | 34 | 0.25 | 32 | 0.27 | 35 | 0.26 | 35 |
E1 | 0.27 | 32 | 0.28 | 27 | 0.25 | 29 | 0.27 | 32 | 0.27 | 31 |
E2 | 0.28 | 30 | 0.28 | 27 | 0.26 | 28 | 0.28 | 30 | 0.27 | 29 |
E3 | 0.27 | 34 | 0.27 | 32 | 0.25 | 31 | 0.27 | 34 | 0.26 | 34 |
F1 | 0.34 | 16 | 0.32 | 20 | 0.31 | 17 | 0.33 | 16 | 0.32 | 18 |
F2 | 0.39 | 11 | 0.39 | 10 | 0.34 | 11 | 0.38 | 11 | 0.37 | 11 |
G1 | 0.35 | 13 | 0.37 | 11 | 0.34 | 11 | 0.35 | 12 | 0.35 | 13 |
G2 | 0.29 | 28 | 0.30 | 24 | 0.25 | 30 | 0.28 | 28 | 0.28 | 27 |
G3 | 0.40 | 10 | 0.44 | 6 | 0.37 | 9 | 0.40 | 9 | 0.40 | 7 |
G4 | 0.30 | 24 | 0.32 | 19 | 0.27 | 26 | 0.30 | 24 | 0.30 | 23 |
G5 | 0.28 | 29 | 0.29 | 25 | 0.27 | 27 | 0.28 | 27 | 0.28 | 24 |
G6 | 0.34 | 15 | 0.35 | 13 | 0.30 | 19 | 0.34 | 15 | 0.33 | 16 |
G7 | 0.23 | 38 | 0.23 | 37 | 0.22 | 38 | 0.23 | 38 | 0.23 | 38 |
G8 | 0.28 | 31 | 0.28 | 29 | 0.24 | 34 | 0.27 | 31 | 0.27 | 33 |
G9 | 0.29 | 26 | 0.27 | 33 | 0.24 | 35 | 0.28 | 29 | 0.27 | 32 |
References
1. Monastiriotis, V.; Psycharis, Y. Between Equity, Efficiency and Redistribution: An Analysis of Revealed Allocation Criteria of Regional Public Investment in Greece. Eur. Urban. Reg. Stud.; 2014; 21, pp. 445-462. [DOI: https://dx.doi.org/10.1177/0969776412455990]
2. Cheung, S.O.; Yiu, T.W. Are Construction Disputes Inevitable?. IEEE Trans. Eng. Manag.; 2006; 53, pp. 456-470. [DOI: https://dx.doi.org/10.1109/TEM.2006.877445]
3. Mishmish, M.; El-Sayegh, S.M. Causes of Claims in Road Construction Projects in the UAE. Int. J. Constr. Manag.; 2018; 18, pp. 26-33. [DOI: https://dx.doi.org/10.1080/15623599.2016.1230959]
4. Chaphalkar, N.B.; Iyer, K.C.; Patil, S.K. Prediction of Outcome of Construction Dispute Claims Using Multilayer Perceptron Neural Network Model. Int. J. Proj. Manag.; 2015; 33, pp. 1827-1835. [DOI: https://dx.doi.org/10.1016/j.ijproman.2015.09.002]
5. Naji, K.K.; Mansour, M.M.; Gunduz, M. Methods for Modeling and Evaluating Construction Disputes: A Critical Review. IEEE Access; 2020; 8, pp. 45641-45652. [DOI: https://dx.doi.org/10.1109/ACCESS.2020.2976109]
6. Mitropoulos, P.; Howell, G. Model for Understanding, Preventing, and Resolving Project Disputes. J. Constr. Eng. Manag.; 2001; 127, pp. 223-231. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(2001)127:3(223)]
7. Mohammadi, S.; Birgonul, M.T. Preventing Claims in Green Construction Projects through Investigating the Components of Contractual and Legal Risks. J. Clean. Prod.; 2016; 139, pp. 1078-1084. [DOI: https://dx.doi.org/10.1016/j.jclepro.2016.08.153]
8. Aibinu, A.A.; Ling, F.Y.Y.; Ofori, G. Structural Equation Modelling of Organizational Justice and Cooperative Behaviour in the Construction Project Claims Process: Contractors’ Perspectives. Constr. Manag. Econ.; 2011; 29, pp. 463-481. [DOI: https://dx.doi.org/10.1080/01446193.2011.564195]
9. Olalekan, O.T.; Ariffin, H.L.B.T.; Ali, K.N.; Raslim, F.M.; Mohamad, M.B. Bibliometric Analysis of Construction Dispute. Malays. Constr. Res. J. Spec. Issue; 2021; 12, 64.
10. Ali, B.; Zahoor, H.; Nasir, A.R.; Maqsoom, A.; Khan, R.W.A.; Mazher, K.M. BIM-Based Claims Management System: A Centralized Information Repository for Extension of Time Claims. Autom. Constr.; 2020; 110, 102937. [DOI: https://dx.doi.org/10.1016/j.autcon.2019.102937]
11. Arditi, D.; Pattanakitchamroon, T. Selecting a Delay Analysis Method in Resolving Construction Claims. Int. J. Proj. Manag.; 2006; 24, pp. 145-155. [DOI: https://dx.doi.org/10.1016/j.ijproman.2005.08.005]
12. Yusuwan, N.M.; Adnan, H. Issues Associated with Extension of Time (EoT) Claim in Malaysian Construction Industry. Procedia Technol.; 2013; 9, pp. 740-749. [DOI: https://dx.doi.org/10.1016/j.protcy.2013.12.082]
13. Ballesteros-Pérez, P.; Rojas-Céspedes, Y.A.; Hughes, W.; Kabiri, S.; Pellicer, E.; Mora-Melià, D.; del Campo-Hitschfeld, M.L. Weather-Wise: A Weather-Aware Planning Tool for Improving Construction Productivity and Dealing with Claims. Autom. Constr.; 2017; 84, pp. 81-95. [DOI: https://dx.doi.org/10.1016/j.autcon.2017.08.022]
14. Yousefi, V.; Yakhchali, S.H.; Khanzadi, M.; Mehrabanfar, E.; Šaparauskas, J. Proposing a Neural Network Model to Predict Time and Cost Claims in Construction Projects. J. Civ. Eng. Manag.; 2016; 22, pp. 967-978. [DOI: https://dx.doi.org/10.3846/13923730.2016.1205510]
15. Chau, K.W. Application of a PSO-Based Neural Network in Analysis of Outcomes of Construction Claims. Autom. Constr.; 2007; 16, pp. 642-646. [DOI: https://dx.doi.org/10.1016/j.autcon.2006.11.008]
16. Cakmak, E.; Cakmak, P.I. An Analysis of Causes of Disputes in the Construction Industry Using Analytical Network Process. Procedia Soc. Behav. Sci.; 2014; 109, pp. 183-187. [DOI: https://dx.doi.org/10.1016/j.sbspro.2013.12.441]
17. Iskandar,; Hardjomuljadi, S.; Sulistio, H. The Most Influencing Factors on the Causes of Construction Claims and Disputes in the EPC Contract Model of Infrastructure Projects in Indonesia. Rev. Int. Geogr. Educ. (RIGEO); 2021; 11, pp. 80-91.
18. Abdul Nabi, M.; El-adaway, I.H. Understanding Disputes in Modular Construction Projects: Key Common Causes and Their Associations. J. Constr. Eng. Manag.; 2022; 148, 04021184. [DOI: https://dx.doi.org/10.1061/(ASCE)CO.1943-7862.0002208]
19. Bakhary, N.A.; Adnan, H.; Ibrahim, A. A Study of Construction Claim Management Problems in Malaysia. Procedia Econ. Financ.; 2015; 23, pp. 63-70. [DOI: https://dx.doi.org/10.1016/S2212-5671(15)00327-5]
20. Kisi, K.P.; Lee, N.; Kayastha, R.; Kovel, J. Alternative Dispute Resolution Practices in International Road Construction Contracts. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2020; 12, 04520001. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000373]
21. Shen, W.; Tang, W.; Yu, W.; Duffield, C.F.; Hui, F.K.P.; Wei, Y.; Fang, J. Causes of Contractors’ Claims in International Engineering-Procurement-Construction Projects. J. Civ. Eng. Manag.; 2017; 23, pp. 727-739. [DOI: https://dx.doi.org/10.3846/13923730.2017.1281839]
22. Ibraheem, R.A.R.; Mahjoob, A.M.R. Facilitating Claims Settlement Using Building Information Modeling in the School Building Projects. Innov. Infrastruct. Solut.; 2022; 7, pp. 1-17. [DOI: https://dx.doi.org/10.1007/s41062-021-00646-2]
23. Abdul-Malak, M.A.U.; El-Saadi, M.M.H.; Abou-Zeid, M.G. Process Model for Administrating Construction Claims. J. Manag. Eng.; 2002; 18, pp. 84-94. [DOI: https://dx.doi.org/10.1061/(ASCE)0742-597X(2002)18:2(84)]
24. Al-Sabah, S.S.J.A.; Fereig, S.M.; Hoare, D.J. A Database Management System to Document and Analyse Construction Claims. Adv. Eng. Softw.; 2003; 34, pp. 477-491. [DOI: https://dx.doi.org/10.1016/S0965-9978(03)00044-9]
25. Barman, A.; Charoenngam, C. Decisional Uncertainties in Construction Projects as a Cause of Disputes and Their Formal Legal Interpretation by the Courts: Review of Legal Cases in the United Kingdom. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2017; 9, 04517011. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000222]
26. Chan, E.H.W.; Suen, H.C.H. Disputes and Dispute Resolution Systems in Sino-Foreign Joint Venture Construction Projects in China. J. Prof. Issues Eng. Educ. Pract.; 2005; 131, pp. 141-148. [DOI: https://dx.doi.org/10.1061/(ASCE)1052-3928(2005)131:2(141)]
27. Chan, E.H.; Suen, H.C.; Chan, C.K. MAUT-Based Dispute Resolution Selection Model Prototype for International Construction Projects. J. Constr. Eng. Manag.; 2006; 132, pp. 444-451. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(2006)132:5(444)]
28. Cheung, S.O.; Pang, K.H.Y. Anatomy of Construction Disputes. J. Constr. Eng. Manag.; 2013; 139, pp. 15-23. [DOI: https://dx.doi.org/10.1061/(ASCE)CO.1943-7862.0000532]
29. Cheung, S.O.; Suen, H.C.H. A Multi-Attribute Utility Model for Dispute Resolution Strategy Selection. Constr. Manag. Econ.; 2002; 20, pp. 557-568. [DOI: https://dx.doi.org/10.1080/01446190210157568]
30. Cheung, S.O.; Li, K.; Levina, B. Paradox of Bias and Impartiality in Facilitating Construction Dispute Resolution. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2019; 11, 04519007. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000295]
31. Diekmann, J.E.; Girard, M.J. Are Contract Disputes Predictable?. J. Constr. Eng. Manag.; 1995; 121, pp. 355-363. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(1995)121:4(355)]
32. Gardiner, P.D.; Simmons, J.E.L. Conflict in Small- and Medium-Sized Projects: Case of Partnering to the Rescue. J. Manag. Eng.; 1998; 14, pp. 35-40. [DOI: https://dx.doi.org/10.1061/(ASCE)0742-597X(1998)14:1(35)]
33. Gould, N. Alternative Dispute Resolution in the UK Construction Industry. Proceedings of the 14th Annual ARCOM Conference; Reading, UK, 9–11 September 1998; Volume 2.
34. Ho, S.P.; Liu, L.Y. Analytical Model for Analyzing Construction Claims and Opportunistic Bidding. J. Constr. Eng. Manag.; 2004; 130, pp. 94-104. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(2004)130:1(94)]
35. Ilter, A.D.; Bakioglu, G. Modeling the Relationship between Risk and Dispute in Subcontractor Contracts. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2018; 10, 04517022. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000246]
36. Jahren, C.T.; Dammeier, B.F. Investigation into Construction Disputes. J. Manag. Eng.; 1990; 6, pp. 39-46. [DOI: https://dx.doi.org/10.1061/(ASCE)9742-597X(1990)6:1(39)]
37. Kartam, S. Generic Methodology for Analyzing Delay Claims. J. Constr. Eng. Manag.; 1999; 125, pp. 409-419. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(1999)125:6(409)]
38. Kilian, J.J.; Gibson, G.E.; Asce, M. Construction Litigation for the U.S. Naval Facilities Engineering Command, 1982–2002. J. Constr. Eng. Manag.; 2005; 131, pp. 945-952. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(2005)131:9(945)]
39. Kululanga, G.K.; Kuotcha, W.; Mccaffer, R.; Edum-Fotwe, F. Construction Contractors’ Calaim Process Framework. J. Constr. Eng. Manag.; 2001; 127, pp. 309-314. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(2001)127:4(309)]
40. Kumaraswamy, M.M. Consequences of Construction Conflict: A Hong Kong Perspective. J. Manag. Eng.; 1998; 14, pp. 66-74. [DOI: https://dx.doi.org/10.1061/(ASCE)0742-597X(1998)14:3(66)]
41. Ren, Z.; Anumba, C.J. Learning in Multi-Agent Systems: A Case Study of Construction Claims Negotiation. Adv. Eng. Inform.; 2002; 16, pp. 265-275. [DOI: https://dx.doi.org/10.1016/S1474-0346(03)00015-6]
42. Ren, Z.; Anumba, C.J.; Ugwu, O.O. The Development of a Multi-Agent System for Construction Claims Negotiation. Proceedings of the Advances in Engineering Software; Elsevier Ltd.: Amsterdam, The Netherlands, 2003; Volume 34, pp. 683-696.
43. Ren, Z.; Anumba, C.J.; Ugwu, O.O. Negotiation in a Multi-Agent System for Construction Claims Negotiation. Appl. Artif. Intell.; 2002; 16, pp. 359-394. [DOI: https://dx.doi.org/10.1080/08839510290030273]
44. Scott, S.; Harris, R.A. United Kingdom Construction Claims: Views of Professionals. J. Constr. Eng. Manag.; 2004; 130, pp. 734-741. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(2004)130:5(734)]
45. Semple, C.; Hartman, F.T.; Jergeas, G. Construction Claims and Disputes: Causes and Cost/Time Overruns. J. Constr. Eng. Manag.; 1994; 120, pp. 785-795. [DOI: https://dx.doi.org/10.1061/(ASCE)0733-9364(1994)120:4(785)]
46. Stamatiou, D.R.I.; Kirytopoulos, K.A.; Ponis, S.T.; Gayialis, S.; Tatsiopoulos, I. A Process Reference Model for Claims Management in Construction Supply Chains: The Contractors’ Perspective. Int. J. Constr. Manag.; 2019; 19, pp. 382-400. [DOI: https://dx.doi.org/10.1080/15623599.2018.1452100]
47. Treacy, T.B. Use of Alternative Dispute Resolution in the Construction Industry. J. Manag. Eng.; 1995; 11, pp. 58-63. [DOI: https://dx.doi.org/10.1061/(ASCE)0742-597X(1995)11:1(58)]
48. Vidogah, W.; Ndekugri, I. Improving Management of Claims: Contractors’ Perspective. J. Manag. Eng.; 1997; 13, pp. 37-44. [DOI: https://dx.doi.org/10.1061/(ASCE)0742-597X(1997)13:5(37)]
49. Viswanathan, S.K.; Panwar, A.; Kar, S.; Lavingiya, R.; Jha, K.N. Causal Modeling of Disputes in Construction Projects. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2020; 12, 04520035. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000432]
50. Wong, P.S.P.; Maric, D. Causes of Disputes in Construction Planning Permit Applications. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2016; 8, 04516006. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000197]
51. Yogeswaran, K.; Kumaraswamy, M.M.; Miller, D.R.A. Claims for Extensions of Time in Civil Engineering Projects. Constr. Manag. Econ.; 1998; 16, pp. 283-293. [DOI: https://dx.doi.org/10.1080/014461998372312]
52. Yuan, H.; Ma, H. Game Analysis in the Construction Claim Negotiations. Proceedings of the Procedia Engineering; Elsevier: Amsterdam, The Netherlands, 2012; Volume 28, pp. 586-593.
53. Zaneldin, E.K. Construction Claims in United Arab Emirates: Types, Causes, and Frequency. Int. J. Proj. Manag.; 2006; 24, pp. 453-459. [DOI: https://dx.doi.org/10.1016/j.ijproman.2006.02.006]
54. Ayyub, B.M. Risk Analysis in Engineering and Economics; 2nd ed. CRC Press, Taylor and Francis Group: Boca Raton, FL, USA, 2014.
55. Creswell, J.W. Research Design. Qualitative, Quantitative and Mixed Methods Approaches; 4th ed. Sage Publications: Thousand Oaks, CA, USA, 2014.
56. Arantes, A.; Ferreira, L.M.D.F. A Methodology for the Development of Delay Mitigation Measures in Construction Projects. Prod. Plan. Control; 2021; 32, pp. 228-241. [DOI: https://dx.doi.org/10.1080/09537287.2020.1725169]
57. Keng, T.C.; Mansor, N.; Ching, Y.K. An Exploration of Cost Overrun in Building Construction Projects. Glob. Bus. Manag. Res. Int. J.; 2018; 10, pp. 638-646.
58. Antoniou, F.; Aretoulis, G.N.; Konstantinidis, D.K.; Kalfakakou, G.P. An Empirical Study of Researchers’ and Practitioners’ Views on Compensating Major Highway Project Contractors. Int. J. Manag. Decis. Mak.; 2013; 12, pp. 351-375. [DOI: https://dx.doi.org/10.1504/IJMDM.2013.056883]
59. Antoniou, F.; Konstantinidis, D.; Aretoulis, G.N. Application of the Multi Attribute Utility Theory for the Selection of Project Procurement System for Greek Highway Projects. Int. J. Manag. Decis. Mak.; 2016; 15, pp. 83-112. [DOI: https://dx.doi.org/10.1504/IJMDM.2016.077761]
60. Noorzai, E. Performance Analysis of Alternative Contracting Methods for Highway Construction Projects: Case Study for Iran. J. Infrastruct. Syst.; 2020; 26, 04020003. [DOI: https://dx.doi.org/10.1061/(ASCE)IS.1943-555X.0000528]
61. Aretoulis, G.N.; Papathanasiou, J.; Antoniou, F. PROMETHEE-Based Ranking of Project Managers Based on the Five Personality Traits. Kybernetes; 2020; 49, pp. 1083-1102. [DOI: https://dx.doi.org/10.1108/K-10-2018-0551]
62. Antoniou, F.; Demertzidou, F.; Mentzelou, P.; Konstantinidis, D. Energy Upgrading of Buildings in Greece with Eco-Materials: An Investigation of Public Awareness. Proceedings of the IOP Conference Series: Earth and Environmental Science; Institute of Physics, IOP Publishing: Bristol, UK, 2022; Volume 1123.
63. Antoniou, F.; Merkouri, M. Accident Factors per Construction Type and Stage: A Synthesis of Scientific Research and Professional Experience. Int. J. Inj. Contr Saf. Promot.; 2021; 28, pp. 439-453. [DOI: https://dx.doi.org/10.1080/17457300.2021.1930061] [PubMed: https://www.ncbi.nlm.nih.gov/pubmed/34154518]
64. Bryman, A. Social Research Methods; Oxford University Press Inc.: New York, NY, USA, 2012.
65. Amoatey, C.T.; Ankrah, A.N.O. Exploring Critical Road Project Delay Factors in Ghana. J. Facil. Manag.; 2017; 15, pp. 110-127. [DOI: https://dx.doi.org/10.1108/JFM-09-2016-0036]
66. Kaliba, C.; Muya, M.; Mumba, K. Cost Escalation and Schedule Delays in Road Construction Projects in Zambia. Int. J. Proj. Manag.; 2009; 27, pp. 522-531. [DOI: https://dx.doi.org/10.1016/j.ijproman.2008.07.003]
67. Mahamid, I.; Bruland, A.; Dmaidi, N. Causes of Delay in Road Construction Projects. J. Manag. Eng.; 2012; 28, pp. 300-310. [DOI: https://dx.doi.org/10.1061/(ASCE)ME.1943-5479.0000096]
68. Antoniou, F. Delay Risk Assessment Models for Road Projects. Systems; 2021; 9, 70. [DOI: https://dx.doi.org/10.3390/systems9030070]
69. Antoniou, F.; Agrafioti, N.F. Meta-Analysis of Studies on Accident Contributing Factors in the Greek Construction Industry. Sustainability; 2023; 15, 2357. [DOI: https://dx.doi.org/10.3390/su15032357]
70. Holt, G.D. Asking Questions, Analysing Answers: Relative Importance Revisited. Constr. Innov.; 2014; 14, pp. 2-16. [DOI: https://dx.doi.org/10.1108/CI-06-2012-0035]
71. Field, A. Discovering Statistics Using SPSS; SAGE Publications Ltd.: London, UK, 2009.
72. Chen, Y.; Okudan, G.E.; Riley, D.R. Sustainable Performance Criteria for Construction Method Selection in Concrete Buildings. Autom. Constr.; 2010; 19, pp. 235-244. [DOI: https://dx.doi.org/10.1016/j.autcon.2009.10.004]
73. Shojaei, A.; Flood, I.; Moud, H.I.; Hatami, M.; Zhang, X. An Implementation of Smart Contracts by Integrating BIM and Blockchain. Proceedings of the Future Technologies Conference (FTC) 2019; Springer International Publishing: Berlin/Heidelberg, Germany, 2020; pp. 519-527.
74. Di Giuda, G.M.; Giana, P.E.; Pattini, G. The Shortening and the Automation of Payments: The Potentiality of Smart Contract in the AEC Sector. Proc. Int. Struct. Eng. Constr.; 2020; 7, pp. 1-6. [DOI: https://dx.doi.org/10.14455/ISEC.2020.7(2).CON-12]
75. Hamledari, H.; Fischer, M. Role of Blockchain-Enabled Smart Contracts in Automating Construction Progress Payments. J. Leg. Aff. Disput. Resolut. Eng. Constr.; 2021; 13, 04520038. [DOI: https://dx.doi.org/10.1061/(ASCE)LA.1943-4170.0000442]
76. Sonmez, R.; Ahmadisheykhsarmast, S.; Güngör, A.A. BIM Integrated Smart Contract for Construction Project Progress Payment Administration. Autom. Constr.; 2022; 139, 104294. [DOI: https://dx.doi.org/10.1016/j.autcon.2022.104294]
You have requested "on-the-fly" machine translation of selected content from our databases. This functionality is provided solely for your convenience and is in no way intended to replace human translation. Show full disclaimer
Neither ProQuest nor its licensors make any representations or warranties with respect to the translations. The translations are automatically generated "AS IS" and "AS AVAILABLE" and are not retained in our systems. PROQUEST AND ITS LICENSORS SPECIFICALLY DISCLAIM ANY AND ALL EXPRESS OR IMPLIED WARRANTIES, INCLUDING WITHOUT LIMITATION, ANY WARRANTIES FOR AVAILABILITY, ACCURACY, TIMELINESS, COMPLETENESS, NON-INFRINGMENT, MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. Your use of the translations is subject to all use restrictions contained in your Electronic Products License Agreement and by using the translation functionality you agree to forgo any and all claims against ProQuest or its licensors for your use of the translation functionality and any output derived there from. Hide full disclaimer
© 2024 by the authors. Licensee MDPI, Basel, Switzerland. This article is an open access article distributed under the terms and conditions of the Creative Commons Attribution (CC BY) license (https://creativecommons.org/licenses/by/4.0/). Notwithstanding the ProQuest Terms and Conditions, you may use this content in accordance with the terms of the License.
Abstract
Conflicts are frequent within the complex professional environment of the construction industry. If claims cannot be overcome amicably, they result in disputes that lead to litigation. Identification of the causes of these claims and their impact on the duration, cost, and quality of the final project is expected to facilitate the prevention of unsuccessful performance of construction contracts. The novelty of this study is that after codifying the most common causes of construction contract claims derived from the extant literature, they are further investigated in terms of their probability of occurrence and the perceived impact they have on the project completion time, its total cost, and quality. Based on calculated relative importance indices from expert opinion, this paper proposes probability and severity of impact values for 39 common causes of claims in the construction industry. These can be applied to calculate their risk values for stakeholders in public construction contracts to plan mitigation measures for contractual claims. The findings show that the top five highest risk causes of contractual claims in the Greek construction industry are changes in quantities, work, or scope, design quality deficiencies or errors, payment delays, delays in work progress, and the financial failure of the contractor.
You have requested "on-the-fly" machine translation of selected content from our databases. This functionality is provided solely for your convenience and is in no way intended to replace human translation. Show full disclaimer
Neither ProQuest nor its licensors make any representations or warranties with respect to the translations. The translations are automatically generated "AS IS" and "AS AVAILABLE" and are not retained in our systems. PROQUEST AND ITS LICENSORS SPECIFICALLY DISCLAIM ANY AND ALL EXPRESS OR IMPLIED WARRANTIES, INCLUDING WITHOUT LIMITATION, ANY WARRANTIES FOR AVAILABILITY, ACCURACY, TIMELINESS, COMPLETENESS, NON-INFRINGMENT, MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE. Your use of the translations is subject to all use restrictions contained in your Electronic Products License Agreement and by using the translation functionality you agree to forgo any and all claims against ProQuest or its licensors for your use of the translation functionality and any output derived there from. Hide full disclaimer